G.R. No. L-33819, 23 October 1982

FACTS:

Plaintiff-appellant National Power Corporation (NPC) and defendant- appellant National Merchandising Corporation (NAMERCO), the Philippine representative of New York-based International Commodities Corporation, executed a contract of sale of sulfur with a stipulation for liquidated damages in case of breach. Defendant-appellant Domestic Insurance Company executed a performance bond in favor of NPC to guarantee the seller’s obligation. In entering into the contract, Namerco, however, did not disclose to NPC that Namerco’s principal, in a cabled instruction, stated that the sale was subject to availability of a steamer, and contrary to its principal’s instruction, Namerco agreed that non-availability of a steamer was not a justification for non-payment of liquidated damages.

The New York supplier was not able to deliver the sulfur due to its inability to secure shipping space. Consequently, the Government Corporate Counsel rescinded the contract of sale due to the supplier’s non-performance of its obligations, and demanded payment of liquidated damages from both Namerco and the surety. Thereafter, NPC sued for recovery of the stipulated liquidated damages. After trial, the Court of First Instance rendered judgment ordering defendants-appellants to pay solidarity to the NPC reduced liquidated damages with interest.

ISSUE:

Whether NAMERCO exceeded their authority.

RULING:

Yes, NaMerCo exceeded their authority.

The Supreme Court held that before the contract of sale was signed Namerco was already aware that its principal was having difficulties in booking shipping space.

It is being enforced against the agent because article 1897 implies that the agent who acts in excess of his authority is personally liable to the party with whom he contracted.

Moreover, the rule is complemented by article 1898 of the Civil Code which provides that “if the agent contracts in the name of the principal, exceeding the scope of his authority, and the principal does not ratify the contract, it shall be void if the party with whom the agent contracted is aware of the limits of the powers granted by the principal”.

Namerco never disclosed to the Napocor the cabled or written instructions of its principal. For that reason and because Namerco exceeded the limits of its authority, it virtually acted in its own name and not as agent and it is, therefore, bound by the contract of sale which, however, is not enforceable against its principal.

*Case digest by Lowel Dave D. Manuel, JD-4, Andres Bonifacio Law School, S.Y. 2019-2020